Welcome to Web App Builders ("we", "our", "us"). These Terms and Conditions govern your use of our website and services. By engaging our services or accessing our website, you agree to be bound by these Terms and Conditions.

1. Scope of Services

Web App Builders offers a range of digital marketing, design, development, and maintenance services. Specific details of the services provided will be outlined in individual contracts or agreements.

2. Project Agreements and Contracts

All projects will be subject to a separate agreement outlining the project scope, deliverables, timelines, payment terms, and other relevant details. These agreements are legally binding and take precedence over these general Terms and Conditions.

3. Payments and Fees

Quotes and Pricing: Our fees are determined by the scope of work and are subject to change based on project revisions or additional services.

Invoicing and Payment: Payments are typically made in stages according to the project milestones. Invoices must be paid within 30 days of issuance. Late payments may incur a penalty.

Taxes: All fees are exclusive of VAT or other applicable taxes unless stated otherwise. Clients are responsible for any such taxes.

4. Confidentiality

We maintain strict confidentiality regarding all client information. Non-disclosure agreements (NDAs) will be executed upon request to protect sensitive information.

5. Intellectual Property Rights

Client's Intellectual Property: Clients retain ownership of their pre-existing intellectual property provided to us for project purposes.

New Intellectual Property: Any intellectual property created by us during the project will belong to the client upon full payment, unless otherwise specified in the contract.

Rights to Use: We reserve the right to use non-confidential project materials for marketing purposes, such as portfolio presentations, unless explicitly restricted in the contract.

6. Revisions and Change Requests

Revisions and change requests must be documented in writing and agreed upon by both parties. Additional fees may apply for extensive changes beyond the original project scope.

7. Project Timelines and Delivery

We will make every effort to meet agreed-upon project timelines. However, delays caused by factors outside our control, such as client unresponsiveness or third-party issues, may impact delivery dates. We will communicate any such delays as soon as they are identified.

8. Client Responsibilities

Clients are responsible for providing accurate and timely information required for project completion. Any delays or issues caused by incomplete or inaccurate information may affect project timelines and costs.

9. Warranties and Disclaimers

Limited Warranty: We warrant that our services will be provided with reasonable care and skill. This warranty applies for 30 days following project completion.

No Guarantees: We do not guarantee specific results or outcomes, such as SEO rankings or sales increases, as these depend on various factors beyond our control.

Limitation of Liability: We are not liable for any indirect, incidental, or consequential damages arising from the use of our services or website.

10. Termination

Either party may terminate a project agreement with written notice. In case of termination, the client is responsible for payment for work completed up to the termination date.

11. Governing Law

These Terms and Conditions and all project agreements are governed by and construed in accordance with the laws of England and Wales. Any disputes arising from these Terms and Conditions or project agreements will be subject to the exclusive jurisdiction of the courts in England and Wales.

12. Changes to Terms and Conditions

We reserve the right to modify these Terms and Conditions at any time. Any changes will be posted on our website, and continued use of our services or website constitutes acceptance of the updated Terms and Conditions.

13. Contact Information

For any questions or concerns regarding these Terms and Conditions, please contact us at:

Email:

Phone:

Address:

Please ensure you read these Terms and Conditions carefully and understand their implications before engaging our services or accessing our website. If you do not agree with any part of these Terms and Conditions, do not use our services or website.